Expert advice in minutes not days. Register it's free and ask your first question now.
Ask a Question
is a free community help desk for construction professionals run by
. A library of high-quality questions from real users with answers delivered and curated by industry experts.
Health and Safety
Legal and Disputes
NEC3 and NEC4 Contracts
Testing and Defects
Risk and Insurance
Secondary X, W and Y options
Planning and Architecture
Register its Free
NEC ECC: Option X5 and X7 - Sectional Completion
I have the options X5 and X7, Sectional Completion and Delay damages.
I recognise that the Project Manager can change the key dates as stated within core clause 14.3, subsequently a compensation event 60.1(4) but I see that key dates are the the condition stated within Contract data 11.2(9).
Are key dates the same reference to the X5 option, sectional completion dates stated within Contract data, if not can the X5 Sectional completion dates be moved by the Project Manager without acceleration or Compensation Events.
to add a comment.
to answer this question.
No - the rules around Sectional Completion are the same as Completion Date i.e. only agreed acceleration can ever bring forward a sectional Completion Date and an implemented compensation event move it later. It is only a Key Date that can be instructed earlier and then assessed as a compensation event.
For what it is worth, I don't think the contract should allow this, I think Key Dates should be treated the same way as Completion that it can only be brought forward by agreed acceleration but that is not what the contract says. The risk to the Contractor is that it will be agreed at a lower value than the Contractor agrees and then only senior representatives (under NEC4) or adjudication can then over turn that.
to add a comment.
Want to improve your knowledge?
Try one of our Free Trials in NEC3, NEC4, JCT or Procurement!
Order answers by